1. Introduction

Welcome to the official website of Sri Sai Swastik Constructions. By accessing or using our website, services, or contacting us for construction-related projects, you agree to comply with and be bound by these Terms and Conditions. Please read them carefully before proceeding.

2. Services Offered

Sri Sai Swastik Constructions provides services in:

  • Residential, commercial, and IT building construction
  • Redevelopment and renovation
  • Villas, bungalows, and customized projects
  • Architectural and structural design support

The scope of work, timelines, and costs will be agreed upon through a written contract for each project.

3. Use of Website

  • All content, including text, images, and designs, is the property of Sri Sai Swastik Constructions and may not be copied, reproduced, or distributed without prior written consent.
  • Users may not misuse the website by uploading harmful material, attempting unauthorized access, or engaging in fraudulent activities.

4. Project Agreements

  • Any project undertaken will be governed by a separate Construction Agreement/Work Order signed between the client and Sri Sai Swastik Constructions.
  • This agreement will clearly define project scope, timelines, cost estimates, payment schedules, and responsibilities of both parties.
  • Modifications, if any, will require mutual written consent.

5. Payments & Pricing

  • Pricing will be based on the agreed scope of work and prevailing market rates.
  • Payment schedules will be outlined in the project contract.
  • Delayed payments may lead to suspension of work until dues are cleared.

6. Timelines & Delivery

  • We strive to complete projects on the agreed timelines. However, delays may occur due to factors beyond our control, such as government approvals, natural calamities, labor strikes, or material shortages.
  • In such cases, clients will be duly informed, and revised timelines will be provided.

7. Liability

  • While we ensure the highest quality standards, Sri Sai Swastik Constructions is not liable for indirect, incidental, or consequential damages arising from project delays, external approvals, or force majeure events.
  • Structural and material warranties (if applicable) will be covered as per manufacturer or supplier terms.

8. Third-Party Collaborations

We may collaborate with architects, structural consultants, and subcontractors to execute projects. These collaborations are chosen carefully, and we remain responsible for overall project delivery.

9. Intellectual Property

All project designs, layouts, and plans created by Sri Sai Swastik Constructions remain our intellectual property unless explicitly transferred under a written agreement.

10. Termination of Services

  • Either party may terminate a project contract by providing written notice, subject to the terms mentioned in the signed agreement.
  • In case of termination, payments for work completed till the date of termination must be cleared by the client.

11. Governing Law

These Terms & Conditions are governed by the laws of India. Any disputes shall be subject to the jurisdiction of the courts in Chennai, Tamil Nadu.

12. Contact Us

For any queries regarding these Terms & Conditions, please reach out to us:

📍 Sri Sai Swastik Constructions
No. 23, Darga Road, Essa Pallavaram,
Chennai – 600043, Tamil Nadu, India

📞 +91 98412 69170 | +91 82480 65565
📧 srisaiswastikconstructions@gmail.com